Terms & Conditions
MyTrentini – Website Terms of Use
Effective Date: 23.03.2026
These Terms & Conditions (“Terms”) govern access to and use of the website www.mytrentini.com (“Website”).
The Website is owned and operated by:
Trentini Spain SL
Registered in Spain
Registro Mercantil: B56249162
EUID: ES29023.000621879
Málaga, Spain
Email: info@mytrentini.com
By accessing or using this Website, you agree to these Terms.
1. PURPOSE OF THE WEBSITE
1.1. The Website is an informational and pre-contractual platform designed to:
- present interior concepts and style directions;
- allow users to upload apartment layouts;
- provide indicative budget orientations;
- initiate communication with Trentini Spain SL.
1.2. The Website is not an e-commerce platform.
1.3. No products are sold directly through the Website.
1.4. Any clickable offers, visualizations, moodboards, pricing ranges, or estimates are indicative only and do not constitute a binding commercial offer.
2. NO ONLINE SALES – CONTRACT FORMATION
2.1. A binding purchase contract is concluded only after:
- issuance of a formal written proposal or invoice by Trentini Spain SL; and
- receipt of the required advance payment.
2.2. Submission of a layout, request, or inquiry through the Website does not create a contractual obligation.
2.3. All sales are governed by separate written commercial documentation provided directly to the Client.
3. CUSTOM-MADE PRODUCTS – NO RIGHT OF WITHDRAWAL
3.1. All products supplied by Trentini Spain SL are manufactured or configured specifically for each individual project.
3.2. Products are made-to-order and produced after order confirmation.
3.3. In accordance with Article 103(c) of Real Decreto Legislativo 1/2007, the right of withdrawal does not apply to goods made according to the consumer’s specifications or clearly personalized.
3.4. Once an order is confirmed and production has commenced, cancellation is not permitted.
4. PROJECT COMMITMENT FEE (IF APPLICABLE)
4.1. Trentini Spain SL reserves the right, at its sole discretion, to request a Project Commitment Fee prior to commencing customization, detailed specification, or measurement services.
4.2. The Project Commitment Fee:
- constitutes payment for consulting, specification preparation, and professional time;
- is non-refundable;
- may be credited toward the final order value if the full project proceeds.
4.3. The Company may waive this fee at its discretion.
5. CLIENT RESPONSIBILITY FOR PLANS AND MEASUREMENTS
5.1. The Client is solely responsible for the accuracy and completeness of all plans, dimensions, and technical documentation provided.
5.2. The Company is not liable for consequences arising from incorrect or incomplete measurements supplied by the Client.
5.3. If the Client is uncertain about measurements, professional on-site measurement services may be offered after payment of the Project Commitment Fee.
5.4. If products cannot be installed or do not fit due to incorrect measurements provided by the Client, all related costs shall be borne by the Client.
6. DELIVERY AND INSTALLATION
6.1. Delivery may include white-glove service (unloading, unpacking, assembly, removal of packaging), as specified in the individual order documentation.
6.2. Installation includes furniture assembly only and excludes connection to electrical, plumbing, or other engineering systems unless expressly agreed in writing.
6.3. If access conditions prevent delivery or installation (e.g., inability to move furniture through doors, staircases, elevators, or windows), the associated risks and additional costs are borne by the Client.
6.4. Installation may be performed by third-party contractors engaged by Trentini Spain SL.
6.5. Risk passes to the Client upon delivery. Ownership transfers only after full payment.
7. DELIVERY TIMEFRAMES
7.1. Estimated delivery and installation timelines are provided in writing.
7.2. A delay of up to two (2) weeks beyond the estimated completion date shall not constitute a material breach.
7.3. Delays caused by manufacturers, logistics providers, force majeure events, or circumstances beyond reasonable control shall not give rise to cancellation rights.
8. WARRANTIES
8.1. For private consumers (B2C), a legal warranty of three (3) years applies in accordance with Spanish law.
8.2. For business clients (B2B), a two (2) year warranty applies unless otherwise agreed.
8.3. Warranty does not apply to:
- normal wear and tear;
- improper use;
- damage caused by third parties;
- incorrect installation not performed by the Company.
9. INTELLECTUAL PROPERTY
9.1. All designs, moodboards, renderings, visualizations, layouts, and technical drawings remain the intellectual property of Trentini Spain SL.
9.2. Such materials may not be reproduced, shared, or used for procurement from third parties without written consent.
10. MARKETING USE OF PROJECT IMAGES
10.1. The Company may photograph completed projects.
10.2. Images may be used for marketing and promotional purposes, provided no personal data, names, or exact addresses are disclosed.
10.3. Clients may object in writing prior to installation.
11. LIMITATION OF LIABILITY
11.1. The Company shall not be liable for indirect or consequential damages.
11.2. Liability is limited to the value of the specific order in question.
11.3. Nothing in these Terms excludes liability where exclusion is not permitted under applicable law.
12. GOVERNING LAW AND JURISDICTION
12.1. These Terms are governed by Spanish law.
12.2. For consumers (B2C), disputes shall be submitted to the courts of the consumer’s domicile.
12.3. For business clients (B2B), disputes shall be subject to the exclusive jurisdiction of the courts of Málaga, Spain.
13. DATA PROTECTION
13.1. Personal data is processed in accordance with applicable data protection laws and the Company’s Privacy Policy.
14. FINAL PROVISIONS
14.1. If any provision is found invalid, the remaining provisions remain in force.
14.2. Trentini Spain SL reserves the right to update these Terms at any time.
Effective Date: 23.03.2026
These Terms & Conditions (“Terms”) govern access to and use of the website www.mytrentini.com (“Website”).
The Website is owned and operated by:
Trentini Spain SL
Registered in Spain
Registro Mercantil: B56249162
EUID: ES29023.000621879
Málaga, Spain
Email: info@mytrentini.com
By accessing or using this Website, you agree to these Terms.
1. PURPOSE OF THE WEBSITE
1.1. The Website is an informational and pre-contractual platform designed to:
- present interior concepts and style directions;
- allow users to upload apartment layouts;
- provide indicative budget orientations;
- initiate communication with Trentini Spain SL.
1.2. The Website is not an e-commerce platform.
1.3. No products are sold directly through the Website.
1.4. Any clickable offers, visualizations, moodboards, pricing ranges, or estimates are indicative only and do not constitute a binding commercial offer.
2. NO ONLINE SALES – CONTRACT FORMATION
2.1. A binding purchase contract is concluded only after:
- issuance of a formal written proposal or invoice by Trentini Spain SL; and
- receipt of the required advance payment.
2.2. Submission of a layout, request, or inquiry through the Website does not create a contractual obligation.
2.3. All sales are governed by separate written commercial documentation provided directly to the Client.
3. CUSTOM-MADE PRODUCTS – NO RIGHT OF WITHDRAWAL
3.1. All products supplied by Trentini Spain SL are manufactured or configured specifically for each individual project.
3.2. Products are made-to-order and produced after order confirmation.
3.3. In accordance with Article 103(c) of Real Decreto Legislativo 1/2007, the right of withdrawal does not apply to goods made according to the consumer’s specifications or clearly personalized.
3.4. Once an order is confirmed and production has commenced, cancellation is not permitted.
4. PROJECT COMMITMENT FEE (IF APPLICABLE)
4.1. Trentini Spain SL reserves the right, at its sole discretion, to request a Project Commitment Fee prior to commencing customization, detailed specification, or measurement services.
4.2. The Project Commitment Fee:
- constitutes payment for consulting, specification preparation, and professional time;
- is non-refundable;
- may be credited toward the final order value if the full project proceeds.
4.3. The Company may waive this fee at its discretion.
5. CLIENT RESPONSIBILITY FOR PLANS AND MEASUREMENTS
5.1. The Client is solely responsible for the accuracy and completeness of all plans, dimensions, and technical documentation provided.
5.2. The Company is not liable for consequences arising from incorrect or incomplete measurements supplied by the Client.
5.3. If the Client is uncertain about measurements, professional on-site measurement services may be offered after payment of the Project Commitment Fee.
5.4. If products cannot be installed or do not fit due to incorrect measurements provided by the Client, all related costs shall be borne by the Client.
6. DELIVERY AND INSTALLATION
6.1. Delivery may include white-glove service (unloading, unpacking, assembly, removal of packaging), as specified in the individual order documentation.
6.2. Installation includes furniture assembly only and excludes connection to electrical, plumbing, or other engineering systems unless expressly agreed in writing.
6.3. If access conditions prevent delivery or installation (e.g., inability to move furniture through doors, staircases, elevators, or windows), the associated risks and additional costs are borne by the Client.
6.4. Installation may be performed by third-party contractors engaged by Trentini Spain SL.
6.5. Risk passes to the Client upon delivery. Ownership transfers only after full payment.
7. DELIVERY TIMEFRAMES
7.1. Estimated delivery and installation timelines are provided in writing.
7.2. A delay of up to two (2) weeks beyond the estimated completion date shall not constitute a material breach.
7.3. Delays caused by manufacturers, logistics providers, force majeure events, or circumstances beyond reasonable control shall not give rise to cancellation rights.
8. WARRANTIES
8.1. For private consumers (B2C), a legal warranty of three (3) years applies in accordance with Spanish law.
8.2. For business clients (B2B), a two (2) year warranty applies unless otherwise agreed.
8.3. Warranty does not apply to:
- normal wear and tear;
- improper use;
- damage caused by third parties;
- incorrect installation not performed by the Company.
9. INTELLECTUAL PROPERTY
9.1. All designs, moodboards, renderings, visualizations, layouts, and technical drawings remain the intellectual property of Trentini Spain SL.
9.2. Such materials may not be reproduced, shared, or used for procurement from third parties without written consent.
10. MARKETING USE OF PROJECT IMAGES
10.1. The Company may photograph completed projects.
10.2. Images may be used for marketing and promotional purposes, provided no personal data, names, or exact addresses are disclosed.
10.3. Clients may object in writing prior to installation.
11. LIMITATION OF LIABILITY
11.1. The Company shall not be liable for indirect or consequential damages.
11.2. Liability is limited to the value of the specific order in question.
11.3. Nothing in these Terms excludes liability where exclusion is not permitted under applicable law.
12. GOVERNING LAW AND JURISDICTION
12.1. These Terms are governed by Spanish law.
12.2. For consumers (B2C), disputes shall be submitted to the courts of the consumer’s domicile.
12.3. For business clients (B2B), disputes shall be subject to the exclusive jurisdiction of the courts of Málaga, Spain.
13. DATA PROTECTION
13.1. Personal data is processed in accordance with applicable data protection laws and the Company’s Privacy Policy.
14. FINAL PROVISIONS
14.1. If any provision is found invalid, the remaining provisions remain in force.
14.2. Trentini Spain SL reserves the right to update these Terms at any time.